Terms of service

By using Enderon's services and signing up as a Client for any job, task or project, you, the Client, agree to be legally bound by these Terms and Conditions.

Please read these terms carefully. By using the products and/or services of Enderon you agree to abide by these Terms and Conditions.

These Terms and Conditions and any additional Terms of Sale or contract specific to a project, service, special offer or promotion set out the entire agreement between Enderon and the Client.

Enderon

In these terms and conditions, Enderon, the Enderon service, all services related to it, and all text, images, photographs, user interface, look and feel, data and other content included in it from time to time, including without limitation the selection, coordination and arrangement of such content, are referred to as "Enderon", "enderon.co.nz", "us", "we", "website" or "service".

Client

Client is defined as representing one business, company, entity or person. Client may also be referred to as "himself/herself", "his/her", "their" or "site owner" in this document. Client may also refer to the staff member, employee, agent or third party acting on behalf of the Client.

Service

Enderon provides the Client various services including, but not limited to:

• Conversion Rate Optimisation
• App and SaaS development
• API development
• Template website design and development
• Ecommerce development and consulting
• Custom website design and development
• Web and internet consulting
• Website maintenance and security
• Website and email hosting service
• SEO - Search Engine Optimisation service
• Google AdWords / online advertising service

Deliverables

For each project or job, Enderon follows a production process that is divided into stages. For each stage, specific deliverables are produced for the Client, which will be specified in a project brief or job quote where applicable.

A task, job or project will be considered complete where either the Client approves the task, job or project as being completed or where Enderon determines that the task, job or project is complete according to the project scope or task/job definition and parameters as set out in a verbal or written agreement.

Enderon may provide the Client with domain name registration, web and email hosting services, custom website design, website design and consulting services and so on in accordance with the product and/or service the Client has requested.

Project scope

A project scope defines and sets out what work, service, item or feature is to be included and/or completed for the project in question. The descriptions, definitions and parameters in a project scope are intended to be clear to Enderon and the Client, as well as to any third party, to judge and finalise the interpretation of any part of a project scope and the relevant task, job or project.

Estimates

An estimate is an approximation of the hours or fees required to complete or deliver a task, job or project. Any final invoice or fee for the work approved by a Client based on an estimate will usually be close or similar to the estimated figure, excluding variations to the project or changes in scope. However, an estimate is not a fixed price and should not be viewed by a Client as such. An estimate is a guide to the final price only.

Enderon will sometimes use an estimate during the early stages of project discussions or for ad-hoc works where Client and Enderon have together approved this billing or engagement model.

Enderon will usually follow up an estimate by providing a retainer invoice or invoice where the Client has given a general approval for the estimated fee or cost.

Retainer invoices and invoices

A retainer invoice or invoice is a specific fee or price that we set down for the requested task, job or project. It will include parameters and defined deliverables. A retainer invoice or invoice will not vary as it is fixed. Any variations to the retainer invoice or invoice, or requirements requested by the Client, will be quoted separately with a set fee or price for that job, project or task.

Direct email

Enderon provides a direct email link for Clients to use to contact Enderon for an enquiry, callback or change request. If requested, Enderon may issue a proposal with an estimate or invoice in respect of any deliverable proposed to be provided under these Terms and Conditions. Enderon may decide, in its sole discretion, to deny a quotation request or information enquiry.

Proposals, estimates and quotes

In response to a request for service or a specific product or service request, Enderon may produce a proposal that will remain valid and open for acceptance by the Client for up to 30 days, unless otherwise agreed by Enderon from the date of issue, that may include any of the following:

• Creative brief or proposal
• Project scope
• Job/task definition
• Description and features
• Fees and charges
• Any other specifics or terms related to the product, service or special offer

Enderon reserves the right to withdraw a proposal or quote at any time.

By approving any estimate or project contract, verbally or in writing, a Client agrees to be bound by these terms of service and to pay Enderon the agreed fees set out in the quote or project contract when Enderon requests payment or as otherwise set out in the quote or project contract.

Invoices

All pricing is given in New Zealand Dollars.

Enderon's invoices are due 5 days after the date of issue and are payable upon receipt by the Client unless otherwise agreed to in writing.

Any outstanding invoices for work completed or services provided to the Client by Enderon require payment in full due on receipt of the invoice unless otherwise agreed in writing between the parties. On completion of a task, job or project, the Client is obliged to pay the balance of the invoice in full.

Fees due in advance for service

Some services including, but not limited to, hosting, web design and support fees and conversion rate optimisation fees are due in advance for the applicable period as noted in the invoice. Such fees and the related invoice must be paid in full prior to the commencement of the applicable service period, whether one month, one year or 24 months.

Quote, job or project completion

Once a Client approves the job or task to go live, or where Enderon defines the job or task as being completed, an invoice will be issued to the Client with payment on that invoice due immediately unless otherwise agreed to in writing between the parties.

Any warranty work that Enderon will carry out to fix or correct bugs or faults in the website or system as reported by the Client or found by Enderon, that may be covered by warranty or the scope of the task, job or project, will be completed as soon as reasonably possible by Enderon.

A revision, where allowed and applicable, to the design or function of the website or system that may be included in the scope of the task, job or project will be completed as soon as possible by Enderon.

Enderon reserves the right to postpone, delay or refuse warranty fix work, revisions or enhancements to a website or system for the Client if the Client has overdue outstanding invoices for any job, task or project.

Project contract payment milestones

For each project contract, there are payment milestones that will occur at various stages or points during the project timeline. For each payment milestone, a fee is due as set out per contract and will be invoiced at the time of the payment milestone being reached, with payment by the Client on that invoice due immediately unless otherwise agreed to in writing between the parties.

Suspension

If the Client defaults on their payment or otherwise fails to pay their account with Enderon as per the terms under this agreement, Enderon reserves the right to suspend services and to apply administrative fees of $125.00 per hour, plus any other costs that may have been incurred, to reactivate the services.

Refunds

Hosting fees, SEO fees, Google Advertising service fees and all service fees charged, unless otherwise specified, are non-refundable for the term, service or product paid for by the Client.

Termination

If the Client chooses to discontinue the services supplied by Enderon and the Client has paid all monies owed to Enderon, Enderon will help the Client transfer their domain name to another provider or agent if requested to do so by the Client. Charges to the Client may apply if the work required or requested to complete the transfer falls within 5 years of the project launch date as specified by Enderon.

Enderon may opt to discontinue services if an amount payable to Enderon is overdue or to take down a website permanently where an amount payable is overdue by more than 30 days. In any such event, the Client remains liable for the total cost of the contract including all disbursements, unless otherwise agreed in writing between Enderon and the Client.

Enderon may terminate any agreement immediately if the Client breaches any of these Terms and Conditions, if the Client is a company going into insolvent liquidation, or if the Client is a person and is declared bankrupt.

Ownership of the product remains with Enderon until payment in full is made to Enderon by the Client.

Enderon reserves the right to discontinue services and terminate the Client at the sole discretion of Enderon where Enderon provides the Client notice in writing of said termination.

Debt collection

Upon default by the Client in regard to any obligation under their agreement with Enderon and where the Client fails to rectify the default after notification by Enderon, the Client authorises Enderon to notify any debt collection agency of the default and charge said debt collection agency with collecting the outstanding debt owed to Enderon by the Client.

Should this occur, then at Enderon's sole discretion it may terminate the contract and/or service being provided to the Client, at which time the full outstanding balance for the remainder of the minimum term in the relevant agreement or payments shall be due in full.

Enderon, at its sole discretion, may choose to apply to the Disputes Tribunal to have a legal ruling handed down by a judge on whether or not the Client is required to pay Enderon any money relating to overdue invoices and/or costs or time lost by Enderon in the process of pursuing payment for overdue invoices from the Client.

Enderon reserves the right to invoice the Client for debtor administrative processing of the debt and debtor management time incurred by Enderon relating to the matter for the respective Client.

Direct Debit agreements may be offered to a Client on a minimum term or no minimum term basis.

Clients pay an initial payment on the date and for the amount specified on the agreement. Debits then commence on the same day of every month or as per the individual Direct Debit Request agreement.

Minimum term

Should the Client want to end their Direct Debit contract before the agreed minimum term as agreed in the Direct Debit Request Service Agreement with Enderon, the Client is liable to pay immediately the full outstanding balance for the remainder of the minimum term plus any debt collection fee and charges as per the Debt Collection clause.

No minimum term

Direct Debits continue ongoing month to month indefinitely until cancelled. Clients may request to cancel their Direct Debit agreement at any time. Clients must give 90 days' notice when cancelling a no minimum term agreement.

Where the service or work has already been supplied and/or completed, the relevant direct debit charge due for that service or work and all payments will continue to be charged and collected from the Client until the required minimum amount due has been paid to Enderon.

Cancellation of a Direct Debit Request Agreement

Should the Client decide to cancel their Direct Debit Request agreement with Enderon before the minimum term has been completed as agreed with Enderon, the Client is liable to pay the full outstanding balance for the remainder of the minimum term to Enderon plus any debt collection fees and charges as per the Debt Collection clause herein.

Enderon is the copyright owner of all works created or developed by Enderon for a Client unless otherwise agreed to in writing. When payment for the product or service is made in full by the Client for the product or service, the Client is licensed to use the product or service for its intended use within the context of their business and the product itself.

However, the Client is restricted from selling the product or promoting the product as their own unless otherwise agreed in writing with Enderon.

Enderon claims no intellectual property rights to works created by any third party designers or developers that may be used from time to time. Such rights remain with the relevant third party.

As a creator of copyright material, Enderon has the following rights:

• To be attributed when its work is used.
• Not to have its work falsely attributed to someone else.
• Not to have altered work attributed as if it were unaltered.
• Not to have the work treated in a manner that would prejudice Enderon's honour or reputation.

Enderon may display its own copyright and intellectual property notices on any websites that Enderon develops. The Client, or any third parties related to or engaged by the Client, must not remove, obscure, deface or alter such copyright and intellectual property notices except by agreement in writing with Enderon.

The Client agrees that in the provision of web design services by Enderon we may utilise the services of third party contractors, and that we may pass on to such contractors any information or materials, including design brief and data, provided to us by you.

In the event any material necessary for the production of the project must be passed on to a third party, Enderon will incur no liability for losses incurred in transit or due to the delay of the shipper or third party.

Enderon may accept to maintain and secure a website that is not hosted by Enderon's third party. In that case, the Client will refer to Enderon fees and charges for the requested services.

The Client acknowledges that Enderon is providing services to the Client on a non-exclusive basis and that Enderon may provide services and products of the same or a similar nature to any other party, provided that in doing so it does not breach privacy.

Enderon shall be free to reproduce, use, disclose, display, exhibit, transmit, perform, create derivative works and distribute any items unless specifically agreed otherwise. Further, Enderon shall be free to use any ideas, concepts, know-how or techniques acquired in construction of sites for any purpose whatsoever, including but not limited to developing, manufacturing and marketing products and other items incorporating such information unless specifically agreed otherwise.

Enderon retains the right to use the completed project and any preliminary designs for the purpose of design competitions, future publications on design, educational purposes, marketing materials and portfolio. Where applicable, the Client will be given any necessary credit for usage of the project elements.

Limited warranty

Enderon provides a limited warranty for websites and systems that are developed and designed by Enderon. This warranty is valid for up to 90 days from the date of launch of the website or system, or from the date that Enderon determines that the website or system is ready to launch, unless otherwise agreed to in writing between the parties.

This limited warranty applies to works performed by Enderon that are in scope for a project scope and contracted project or that are clearly specified in the applicable written quote.

Where applicable for any bug, problem or fault with the noted or reported function or element that is covered by this limited warranty, where the function or element is deemed to be not working when assessed by Enderon against the project scope or written quote specifications, Enderon will fix the bug, problem or fault in the website or system at no cost to the Client where Enderon determines that the bug, problem or fault is because of recently completed works performed improperly or incompletely by Enderon during the execution of the works in question.

This warranty is voided if the Client or a third party acting on behalf of the Client is issued with FTP, Shell, MySQL or similar access to the website/system hosting or the relevant hosting control panel by Enderon.

This warranty may be voided if a Client or a third party acting on behalf of the Client installs any extensions, plugins or additional software into the website or system without the express written permission and approval of Enderon.

This warranty does not include any issues, faults or incompatibilities that are caused by third party software, systems, extensions, plugins or similar.

Website

Enderon will ensure that any site or application will function correctly at the time of the website development and going live when viewed with the current versions of Mozilla Firefox, Google Chrome and Apple Safari, unless otherwise agreed in writing.

Any warranty or guarantee provided by Enderon for a website is conditional upon the website being hosted by Enderon on hosting servers run and operated by Enderon that have restricted access to the hosting server and/or hosting control panel for the hosting server.

Any warranty or guarantee provided by Enderon for a website is rendered null and void if the Client or any other third party accesses the website or the relevant website server via an FTP connection or hosting control panel.

Enderon can offer no guarantee of correct function with all browser software in future releases of any internet browser. However, Enderon will offer and provide a quote for services to modify the website, where possible, to cause the site to correctly function and/or correctly render in the changed version of an internet browser.

Where any Client, agent or party acting for or on behalf of the Client acts on or in the website or system that causes disruption or error to the website or system, Enderon is not liable and the Client will be liable for any and all costs associated or incurred with fixing the error or disruption.

Search engine optimisation services

Whilst Enderon will try to improve the position of the Client's website in search engine results in response to a search request, we do not warrant that this effort will be successful nor can Enderon warrant the time that the position a search engine will be held.

Enderon cannot be held responsible for any changes to the position of the Client's website in search engine results pursuant to the provision of search engine optimisation services by Enderon.

Copyright and intellectual property

Enderon is not responsible for the contents and data of any website we design for the Client, and upon publication the Client must satisfy themselves that the website will comply with all applicable laws and codes of practice governing the use of websites and related services. This includes the intellectual property and copyright ownership of all material that the Client has provided to us.

Enderon is similarly not responsible for the Client's subsequent use of the site and compliance with various regional legislation.

Domain name

Enderon is not responsible for the Client's choice of domain name and the legal consequences that the domain name use could occur relating to trademark, competition or domain governing laws.

Client's third party

Enderon is not responsible for the performance of the product or service if the Client installs or orders another third party to install anything such as software that would alter or damage the website and its functionality. Furthermore, the Client may be liable for charges or fees incurred by Enderon for the repair of any product or service if the Client or their third party installs any unapproved software into the product or service supplied by Enderon.

Data and proofing

Enderon shall make every effort to ensure the final product is free of grammatical and spelling errors before giving the final product to the Client.

Enderon is not responsible or held liable for any errors contained in the final product after the final product is provided. This remains the final responsibility of the Client.

Enderon cannot take responsibility for any copyright or privacy infringements caused by materials submitted by the Client and reserves the right to refuse use of any such material unless proof of permission is provided if requested.

Loss

In no event will Enderon be liable to any party including the Client for any indirect, punitive, special, incidental or consequential damage or loss, financial or otherwise, in connection with or arising out of these Terms, including for loss of profits, use, data or economic advantage, regardless of how it arises. The Client will indemnify Enderon from and against any claim by any party claiming any such damage against Enderon.

Enderon will not be liable for any costs incurred or compensation for loss of earnings due to the unavailability of the site, servers, software or any material provided by Enderon or its agents or third party partners.

Technology compatibility

Enderon will ensure that any website or application will function correctly on the server to which it is initially installed.

Enderon can offer no guarantee of correct function with all browser software including future releases.

General liabilities

Enderon may from time to time and without notice or liability to the Client suspend any of the services if the reason for doing so is an event beyond the reasonable control of Enderon.

Enderon will not be liable or become involved in any disputes between the site owner and their clients and Enderon cannot be held responsible for any wrongdoing on the part of a site owner.

These terms and conditions and any agreement entered into by Enderon or service provided by Enderon that arises in a dispute or legal matter shall be governed by and interpreted in accordance with the law for the time being enforced in New Zealand, and each party submits to the jurisdiction of New Zealand.